No Waiver Without Clear Intent: Supreme Court Sets Aside Arbitral Award for Violating ‘No Oral Modification’ Clause
This Supreme Court judgment underscores the narrow scope of judicial intervention under Sections 34 and 37 of the Arbitration and Conciliation Act, 1996. It affirms that an arbitral award can be set aside if it violates the fundamental policy of Indian law, principles of natural justice, or the terms of the contract, or if it exhibits patent illegality or perversity that shocks the conscience of the court. The Tribunal must adjudicate within the contractual framework and cannot rewrite the agreement.
Facts Of The Case:
The dispute arose between SEPCO Electric Power Construction Corporation, an EPC contractor, and GMR Kamalanga Energy Ltd., the project owner, concerning the construction of thermal power plants in Odisha. Following delays and disagreements, SEPCO demobilized from the site ...