Conditions Precedent - The Legal Chamber

In a significant ruling, the Supreme Court held that a preliminary issue of limitation, being a mixed question of law and fact, cannot be permanently foreclosed by an arbitrator based on a demurrer. The Court clarified that such a decision on demurrer is not a final adjudication on merits and does not preclude a subsequent examination based on evidence, as it would violate the fundamental mandate of Section 3 of the Limitation Act, 1963. Facts Of The Case: The dispute arose from a Share Subscription Agreement (SSA) dated 23.07.2008 between Urban Infrastructure Real Estate Fund (Petitioner) and Neelkanth Realty Pvt. Ltd. (Respondent). The Petitioner invested Rs. 25 Crore, with a clause stipulating a refund if certain "Conditions Precedent" were not fulfilled within 90 days. The Respondent...

The Supreme Court held that the Power Purchase Agreement's explicit terms govern the parties' rights. The encashment of the performance bank guarantee was valid as the developer failed to seek an extension under the contractual mechanism or issue a mandatory Force Majeure notice. Regulatory commissions cannot rewrite the contractual risk allocation or grant remedies outside the agreed framework. Facts Of The Case: The dispute arose from a Power Purchase Agreement (PPA) executed between Chamundeshwari Electricity Supply Company Ltd. (CESC) and Saisudhir Energy Pvt. Ltd. for a 10 MW solar power project. The PPA stipulated that the developer was to achieve the Commercial Operation Date (COD) within 12 months, preceded by fulfilling certain Conditions Precedent within 240 days. A critical pr...

Tag: Conditions Precedent

Supreme Court Backs Discom: Upholds Right to Encash Bank Guarantee in Delayed Solar Project